STATUTORY INSTRUMENTS.

S.I. No. 371 of 2000.

DUBLIN LIGHT RAIL (LINE C(S) - STORE STREET TO CONNOLLY STATION) ORDER, 2000.

S.I. No. 371 of 2000.

DUBLIN LIGHT RAIL (LINE C(S) - STORE STREET TO CONNOLLY STATION) ORDER, 2000.

ARRANGEMENT OF ARTICLES

PART 1

Preliminary And General

PART 2

Works Provisions

PART 3

Acquisition And Possession Of Land

PART 4

Miscellaneous

SCHEDULES

Schedule 1

Part 1

Description of the works authorised by this Order

Part 2

Further works authorised by this Order

Schedule 2

Land which may be acquired

Schedule 3

Part 1

Buildings etc. to which brackets may be attached

Part 2

Land upon which poles may be erected.

Schedule 4

Basements under public road which may be required

Schedule 5

New roads which may be constructed

Schedule 6

Public roads upon which the light railway works may be carried out

Schedule 7

Rights of way and other easements which may be acquired

Schedule 8

Part 1

Public rights of way which may be extinguished

Part 2

Private rights which may be extinguished

Schedule 9

Rights of way which may be temporarily interrupted

Schedule 10

Land which may be temporarily occupied

Schedule 11

Conditions

S.I. No. 371 of 2000.

DUBLIN LIGHT RAIL (LINE C(S) - STORE STREET TO CONNOLLY STATION) ORDER, 2000.

WHEREAS Córas Iompair Éireann (“the Board”) applied to the Minister for Public Enterprise (“the Minister”) for a light railway order pursuant to section 3 of the Transport (Dublin Light Rail) Act, 1996 ( No. 24 of 1996 );

AND WHEREAS a draft of the proposed Order entitled “Dublin Light Rail -- Line C -- Abbey Street to Connolly Station Order (No. 3) 1999” accompanied the application, pursuant to subsection (2) of the said section 3, together with the other documents referred to in that subsection;

AND WHEREAS an Inquiry was established and an Inspector appointed by warrant of appointment of 19 October 1999, pursuant to section 8 of the said Act;

AND WHEREAS the Inquiry was duly conducted and the Inspector has reported to the Minister on 11 January 2000 and recommended that the application be approved by her insofar as it related to the development from Lower Abbey Street to Store Street stop only, subject to the conditions set out in Chapter 4 of the Report of the Inquiry and the concessions made by the applicant during the Inquiry process;

AND WHEREAS the Minister advised the applicant by letter dated 10 February 2000 that she agreed with the Inspector's findings and accepted his recommendations and approved the application subject to those recommendations;

AND WHEREAS the Minister in that letter indicated to the applicant that she would not make the Order in respect of that approval until an acceptable proposal for a link between Store Street and Connolly Station had been received;

AND WHEREAS, subsequently, the Board applied to the Minister for a light railway order pursuant to section 3 of the Transport (Dublin Light Rail) Act, 1996 ;

AND WHEREAS a draft of a proposed Order entitled “Dublin Light Rail -- Line C(S) -- Store Street to Connolly Station Order, 2000” accompanied the application, pursuant to subsection (2) of the said section 3, together with the other documents referred to in that subsection;

AND WHEREAS an Inquiry was established and an Inspector appointed by warrant of appointment of 4 July 2000, pursuant to section 8 of the said Act;

AND WHEREAS the Inquiry was duly conducted and the Inspector has reported to the Minister on 2 October 2000 and recommended that the application be approved by her subject to the conditions set out in Chapter 4 of the Report of that Inquiry and the concessions made by the applicant during the Inquiry process;

Now, therefore, the Minister for Public Enterprise, in exercise of the powers conferred on her by subsection (2) of section 9 of the Transport (Dublin Light Rail) Act, 1996 , after having considered the matters relevant to the application pursuant to subsection (1) of that section and being of the opinion that application should be granted, order as follows:--

PART 1

Preliminary

Citation.

1. This Order may be cited as the Dublin Light Rail -- Line C(S) -- Store Street to Connolly Station -- Order 2000.

Interpretation.

2. (1) In this Order except where the context otherwise requires

“the Act” means the Transport (Dublin Light Rail) Act, 1996 (No. 24 of 1996) ;

“apparatus” includes any sub-station, inspection chamber, junction box, booster station, pipe, sewer, drain, duct, tunnel, conduit, wire, cable, fibre, insulator or other thing used by a utility for or in connection with the provision of a service to the public;

“authorised works” means the works authorised by this Order;

“the Board” means Córas Iompair Éireann;

“the book of reference” means the book of reference submitted to the Minister for Public Enterprise with the application for this Order;

“deposited plan” means the plan submitted to the Minister for Public Enterprise with the application for this Order;

“light railway” means a way formed above, on or under the ground by parallel rails together with vehicles having wheels flanged or otherwise suitable only for use on and to be guided by such rails the entire being designed to transport passengers mainly in an urban area and to a greater or lesser extent on public roads;

“maintain” includes inspect, repair, adjust, alter, remove, reconstruct, renew and replace and cognate words shall be construed accordingly;

“mechanical power” means electrical or any motive power other than animal power;

“relevant road authority” means a road authority in whose functional area the Board proposes to exercise powers conferred on it by this Order;

“stop” means a halting place where passengers or intending passengers may alight from or board light railway vehicles;

“utility” means any person or body (other than the Board) including a local authority providing services to the public generally or to any section or member of the public pursuant to powers and duties in that behalf contained in any Statute or pursuant to any licence or permit granted pursuant to any Statute;

“works” includes the doing, making, laying down, placing, erection, maintenance, operation and use of anything deemed necessary or desirable for or in connection with the construction, operation, maintenance, efficiency, safety and security of a light railway and authorised expressly or by necessary implication by this Order.

(2) References in this Order to rights over land include references to rights to do or to place or maintain anything in, on, over or under land.

Authorisation.

3. Pursuant to section 9(2) of the Act of 1996, the Minister for Public Enterprise authorises:

(a) the Board to construct, maintain and improve the light railway works specified in this order or any part of it,

(b) the use of the light railway works or any part of it for the purposes of the operation of a light railway, and

(c) the operation, maintenance and improvement of a light railway or any part of it,

in such manner and subject to the such conditions (including the conditions set out in Schedule 11), restrictions and requirements (and on such other terms) as specified in this Order.

Incorporation of enactments

4. The Regulation of Railways Acts 1840 -- 1893 and any other Act relating to railways shall apply to the light railway authorised by this Order so far as they are applicable for the purposes of and are not inconsistent with or varied by the provisions of this Order and the Act together with this Order shall be deemed to be the Special Act for the purposes of those enactments.

PART 2

Works Provisions

Construction of works.

5. (1) Subject to the provisions of this Order, the Board may, on the lines, in the places and according to the levels shown on the deposited plan, do, make, construct and maintain the works specified in Part 1 of the Schedule and all other works necessary or ancillary in connection therewith.

(2) Subject to the provisions of this Order, the Board may, on the lines, in the places and according to the levels shown on the deposited plan, do, make, construct and maintain the further works described in Part 2 of the Schedule and all other works necessary or ancillary thereto.

(3) Subject to section 16 of the Act, the Board may break open a public road having given not less than 7 days prior notice to the relevant road authority and may remove, appropriate and use the soil or other materials therein or thereunder.

General powers of the Board.

6. In constructing or maintaining any of the light railway works the Board may:--

(1) (a) where such works are situated in or adjacent to a public road--

(i) deviate laterally by an amount not exceeding 1.0 metre from the lines or situations shown on the deposited plan

(ii) deviate vertically by an amount not exceeding 0.3 metres upwards or downwards from the levels shown on the deposited plan

(iii) deviate longitudinally by an amount not exceeding 10 metres in respect of any light rail work

(b) where such works are situated otherwise than in or adjacent to a public road

(i) deviate laterally by an amount not exceeding 2.5 metres from the lines or situations shown on the deposited plan

(ii) deviate vertically by an amount not exceeding 0.75 metres upwards from the levels shown on the deposited plan

(iii) deviate vertically by an amount not exceeding 1.5 metres downwards from the levels shown on the deposited plan, and

(iv) deviate longitudinally by an amount not exceeding 10 metres in respect of any light rail work.

(2) The Board may, in constructing or maintaining light railway works, lay down either single or interlacing tracks of parallel rails in places where double tracks are shown on the deposited plan.

Power to alter the layout of public roads.

7. (1) Subject to the provisions of paragraph (2) of this Article the Board may in connection with or for the purpose of light railway works in or adjacent to any public road and in accordance with the deposited plan:--

(a) increase the width of the carriageway of the road by reducing the width of any footway, cycle track, verge or other land within the boundary of the said road; or

(b) alter or interfere with the level of any kerb, footway, cycle track, verge or other land within the boundary of the said road; or

(c) reduce the width of the carriageway of the road; or

(d) carry out works to the carriageway of the road for the purpose of deterring or inhibiting vehicles other than light rail vehicles from passing along the tracks of the light railway.

(2) Before exercising any power under paragraph (1) of this Article, the Board shall obtain the consent of the relevant road authority which consent shall not be unreasonably withheld or delayed.

(3) The works authorised by this Order may be done, made, constructed and maintained in, upon and under the public roads specified in the Schedule 6 to this Order.

Temporary closure of roads.

8. (1) Subject to the provisions of paragraph (2) of this Article, the Board may, for the purpose of carrying out light railway works or for any purpose incidental thereto, request a relevant road authority by order temporarily to close a public road to traffic and the following shall apply in relation to such request:--

(a) the Board shall give to the road authority notice in writing of its requirement to close such public road and such notice shall--

(i) specify the road which is required to be temporarily closed

(ii) state a period for which, in the reasonable opinion of the Board, it is necessary to temporarily close such road

(iii) Give particulars of any alternative route or routes if any which the Board believes will be available while such road is temporarily closed

(iv) contain a brief description of the works which the Board proposes to carry out while such road is temporarily closed;

(b) within 12 days of the receipt by a road authority of the notice referred to in subparagraph (a) of this Article, the road authority shall give at least 14 days notice of its intention to close the road concerned--

(i) in one or more newspapers circulating in the area in which the road is situated, and

(ii) in writing to the Superintendent of the Garda Síochána within whose district the road is situated;

(c) the notice required to be given by sub-paragraph (b) of this paragraph shall

(i) contain the information set out in the notice furnished to road authority by the Board and

(ii) state that objections may be made in writing to the road authority in relation to the proposed temporary closure of the road before a specified date (which date shall not be less than 3 days after the publication of such notice);

(d) a road authority shall consider any objections made to it in writing pursuant to subparagraph (c) of this paragraph and not withdrawn;

(e) where a road authority having complied with subparagraphs (b), (c) and (d) of this paragraph decides to close a public road it shall give at least 7 days notice of its decision to close the road concerned--

(i) in the newspaper or newspapers circulating in the area where the notice of its intention temporarily to close the road was published, and

(ii) in writing to the Superintendent of the Garda Síochána within whose district the road is situated,

and such temporary closure shall not take effect on a date which is earlier than that specified in the notice of intention under subparagraph (b) of this paragraph; the notice of decision required to be given by this sub-paragraph shall contain the information specified in sub-article (a) of this paragraph;

(f) the Board shall provide reasonable access for pedestrians going to or from premises abutting on a public road affected by the exercise of the powers conferred by this Article if there would otherwise be no such access;

(g) the Board shall provide such access for vehicular traffic along the public road affected by the exercise of the powers conferred by this Article as the Board may from time to time consider reasonable having regard to the nature of the works and the need to preserve the safety of persons and vehicles which may be permitted to use the said public road and the Board may impose such restrictions and conditions upon the passage of vehicles as it may consider reasonable in the circumstances.

(2) Paragraph (1) of this Article shall not apply to the carrying out by the Board of emergency works necessary to eliminate or reduce danger or risk to persons or property.

Construction of new roads.

9. (1) The Board may, with the consent of the relevant road authority, construct the new roads specified in the Schedule 5 with all necessary works connected therewith either by way of diversion from or in substitution for an existing public road or as an additional road.

(2) Each new road constructed under this Article shall when completed, unless otherwise agreed between the Board and the road authority, be maintained by and at the expense of the Board for a period of 12 months from the date of completion and at the expiration of that period shall be maintained by and at the expense of the road authority in whose functional area such new road is situated.

(3) Should any dispute occur in relation to any of the provisions of this Article between the Board and the road authority such dispute shall be referred to arbitration in accordance with the provisions of Article 24 of this Order.

Construction of bridges.

10. Wherever the Board is authorised by this Order to construct a bridge to carry a light railway over any public road, motorway or waterway or, as the case may be, to carry any public road over a light railway the following shall apply in relation to the construction and maintenance of such bridge:

(a) where any such bridge carries the light railway, such bridge shall be maintained by the Board at its own expense.

(b) where such bridge carries a public road the Board shall maintain such bridge at its own expense provided however that in relation to the maintenance of a road surface of such bridge the Board and the road authority may enter into agreements upon such terms as may be agreed between them for the maintenance, improvement, or relaying of such road surface whether by the Board, a contractor employed by the Board for that purpose, or by the road authority or any contractor on its behalf.

Fixing of brackets to buildings and erection of poles.

11. (1) The Board may enter upon the lands specified in Part 1 of the Schedule 3 and may attach to any wall, house, building or structure thereon any bracket, cable or wire or other fixture required for or in connection with the construction, operation or maintenance of a light railway.

(2) The Board may enter upon the lands specified in Part 2 of the Schedule 3 and may erect thereon any pole or poles required for or in connection with the construction, operation or maintenance of a light railway.

Underpinning of buildings.

12. (1) The Board may in accordance with the provision of Section 14 of the Act enter on any land and underpin or otherwise strengthen any house, building or structure affected or likely to be affected by light railway works where the Board considers it necessary or expedient to do so for the purpose of preventing or minimising injury, loss or damage to such house building or structure or any part thereof.

(2) Where any house, building, or other structure has been underpinned or strengthened in accordance with the provisions of Section 14 of the Act and this Article, the Board may from time to time thereafter and in accordance with the provisions of that Section 14 and the provisions of this Article re-enter on any land and do such further underpinning or strengthening as the Board may deem necessary or expedient.

Discharge of water.

13. The Board may use any available stream or watercourse or any sewer or drain for the drainage of water in connection with the construction or maintenance of the light railway works and for that purpose may make any convenient connections with any such stream, watercourse, sewer or drain, subject, however, to the following provisions--

(a) the Board shall not discharge any water into any public watercourse, sewer or drain except with the consent of the sanitary authority to which it belongs which consent shall not be unreasonably withheld or delayed and in accordance with such terms and conditions as such sanitary authority may reasonably impose;

(b) the Board shall take such steps as may be reasonably practicable to ensure that any water discharged into any such public watercourse, sewer or drain under the powers conferred on the Board by this Article is free from soil or polluting or deleterious material;

(c) should any dispute occur in relation to any of the provisions of this Article between the Board and the sanitary authority such dispute shall be referred to arbitration in accordance with the provisions of Article 24 of this order.

Temporary light railways.

14. (1) Where the light railway works have been constructed on a public road, the Board may, for the purposes of the maintenance, upgrading or improving of the said light railway works

(a) remove or discontinue the operation of the light railway or

(b) lay, maintain and operate in or near such light railway a temporary light railway in lieu of the aforementioned light railway.

(2) The Board in exercising the power contained in paragraph (1) of this Article shall, before carrying out such works, obtain the consent of the relevant road authority to the carrying out by the Board of such works as aforesaid which consent shall not be unreasonably withheld or delayed.

(3) Where the Board or the road authority is of the opinion that the public road, the subject of the works referred to at paragraph (1) of this Article, should properly be temporarily closed to vehicular traffic then it shall request the road authority temporarily to close to vehicular traffic the said public road and the provisions of Article 8 of this Order shall apply in relation to such temporary closure. Where the road authority is of the opinion that such public road should be temporarily closed to such traffic it shall notify in writing the Board of such opinion whereupon the Board shall furnish a request to such road authority in accordance with the provisions of subparagraph (1) of Article 8 of this Order and the provisions of the said Article shall thenceforth apply in respect of such temporary closure.

Motive power.

15. (1) The light railway shall be operated by mechanical power.

(2) where the light railway is laid on a carriageway then, so far as is practicable, it shall be so constructed and maintained as to ensure that the uppermost surface of the rails of the railway is generally level with the adjacent surface of such carriageway.

(3) The gauge of the light railway shall be nominally 1435mm (4ft 8½ ins).

Period for which the Board is authorised to carry out works.

16. (1) Construction of the works authorised by this Order shall be completed at the end of the period of 5 years beginning on the day upon which this Order comes into force.

(2) Paragraph (1) of this Article shall not apply to any works required for the maintenance or improvement of the light railway works or any of them.

PART 3

Acquisition And Possession Of Land

Power to acquire land.

17. (1) Subject to the provisions of the Act, the Board may acquire compulsorily and use all or such part of the lands shown on the deposited plan and specified in the Schedule 2 as the Board may require for the purposes of the light railway or for purposes incidental or ancillary to such purposes.

(2) Without prejudice to the provisions of Article 20 of this Order and subject to the provisions of the Act, the Board may acquire compulsorily and use all of the basements specified in the Schedule 4 to this Order or such parts thereof as the Board may consider necessary to acquire for the purposes of the light railway works.

Acquisition of easements.

18. Subject to the provisions of the Act, the Board may acquire compulsorily such rights over all or part of the lands shown on the deposited plan and specified in the Schedule 7 as may be required for the purposes of the light railway.

Extinguishment of rights including rights of way.

19. Subject to the provisions of the Act the Board may --

(a) extinguish all public rights of way specified in Part 1 of the Schedule 8 to this Order,

(b) extinguish all private rights including rights of way, if any, specified in Part 2 of the Schedule 8 to this Order.

(c) temporarily stop up the rights of way specified in the Schedule 9 to this Order.

Use of air space.

20. (1) Without prejudice to the provisions of Article 17 of this Order, the Board may enter upon and use so much of the air space over a public road as may reasonably be required for the purposes of or in connection with the light railway or the works authorised by this Order.

(2) The power under paragraph (1) may be exercised in relation to a public road without the Board being required to acquire any part of the public road or any easement or other right in relation to the surface of the public road.

Temporary possession of land.

21. (1) The Board may enter upon and take temporary possession of the lands specified in the Schedule 10 to this Order or any part of such lands.

(2) In particular, but without prejudice to the generality of paragraph (1) of this Article, the Board may--

(a) enter upon and take temporary possession of such land for the provision of working sites and access for construction purposes and for such purposes may construct and remove any structures thereon, cut and remove anything growing on such land or part thereof, and generally do all such things to and on such lands as may be required to adapt it for such working or access.

(b) may enter upon and take temporary possession of a building, part whereof may in exercise of the powers conferred on the Board by the Act and this Order have been compulsorily acquired or interfered with for the purpose of carrying out works on the unacquired or uninterfered with part of such building with a view to minimising the damage or injury done or likely to be done by the acquisition of, removal of or interference with the part of such building so acquired or interfered with.

(3) Before giving up possession of land specified in the Schedule 10 to this Order, the Board shall remove all temporary works and structures constructed by it on the said land and, subject to any agreement to the contrary with the owners and occupiers of the said land, shall restore the said land as far as possible to its former state to the reasonable satisfaction of the owners and occupiers.

(4) The Board shall not be required to acquire any land of which it takes temporary possession pursuant to this Article.

(5) The Board shall pay to the owners and occupiers of land, of which it takes temporary possession by virtue of this Article, such compensation for any loss thereby suffered as though it were loss suffered and the amount of the compensation determined in consequence of the exercise by the Board of a power conferred upon it by section 14 of the Act.

Period in which the Board may compulsorily acquire land and interests in land.

22. (1) The powers conferred on the Board by this Order to acquire compulsorily land or rights over land and the power conferred by Article 21 of this Order to enter upon and take temporary possession of land shall cease at the end of the period of 5 years beginning on the day upon which this Order comes into force.

(2) The powers of the Board compulsorily to acquire land or rights over land shall for the purposes of this Article be deemed to have been exercised if Notice to Treat has been served in respect of such land or rights before the end of the period mentioned in paragraph (1) of this Article.

(3) Notwithstanding paragraph (1) of this Article, the Board shall be entitled to remain in temporary possession of land pursuant to Article 21 of this Order after the end of the period mentioned in paragraph (1) of this Article where possession of such land was taken before the end of such period.

PART 4

Miscellaneous

Relocation of utility apparatus.

23 (1) Wherever the Board is authorised to carry out, do, construct or maintain works by virtue of the Act and this Order and any apparatus of a utility will or may be affected in consequence thereof the following provisions shall apply:--

(a) Where land is acquired by the Board a utility whose apparatus is under, in, over, along or across the said land or any part thereof may and, upon reasonable request by the Board, shall, without unreasonable delay, do one or more of the following:

(i) Remove the apparatus and place it or other apparatus provided in substitution for it in such other position or location as may be agreed with the Board,

(ii) Provide other apparatus in substitution for the existing apparatus and place it in such position or location as may be agreed with the Board, or

(iii) take such further or other steps or make such further or other provision with the agreement of the Board as may secure the apparatus of the utility and the works of the Board and the proper functioning of each of them respectively from mutual interference or damage;

(b) Where the apparatus of a utility is under, in, upon, over, along or across a public road, the utility may and upon reasonable request by the Board shall without unreasonable delay do any one or more of the following:

(i) Remove the apparatus and place it or other apparatus provided in substitution for it in such other position or location as may be agreed with the Board,

(ii) Provide other apparatus in substitution for the existing apparatus and place it in such position or location as may be agreed with the Board,

(iii) Take such further or other steps or make such further or other provision with the agreement of the Board as may secure the apparatus of the utility and the works of the Board and the proper functioning of each of them respectively from mutual interference or damage.

(2) (a) Subject to the provisions of subparagraph (b) of this paragraph, the Board shall pay to a utility an amount equal to the cost reasonably incurred by that utility in or in connection with the discharge by that utility of obligations on it arising pursuant to paragraph (1) of this Article.

(b) (i) Where a utility, in the course of the discharge of obligations arising pursuant to paragraph (1) of this Article, causes its apparatus or any part thereof to be improved whether as to type, construction, design, layout, placement or in any other respect, the sum payable by the Board pursuant to subparagraph (a) of this paragraph shall nevertheless not exceed the cost that would have been reasonably incurred by the utility if the improvement had not been effected.

(ii) Where the discharge by a utility of obligations arising pursuant to paragraph (1) of this Article, results in benefit to the utility, a sum equivalent to the reasonable value of such benefit, as agreed with the Board or in default of agreement determined on arbitration pursuant to Article 24 hereof, shall be deductible by the Board from any sum otherwise payable to the utility pursuant to subparagraph (a) of this paragraph.

(3) A utility may permit the Board to carry out or cause to be carried out such portion of the works as the utility may agree in accordance with such conditions as may be agreed between the Board and the utility, provided, however, that a utility shall not be obliged to enter into any such agreement.

Arbitration.

24. Should any dispute arise between the Board and a utility in relation to the carrying out, doing, construction or maintenance of any of the light railway works authorised by this Order, or in relation to any matter referred to in Article 23 of this Order, the following provisions shall apply:

(a)  The Board and the utility shall use their best endeavour to resolve any such dispute on terms acceptable to the Board and the utility,

(b) If, after such period as the Board or the utility considers reasonable, such dispute has not been resolved to the satisfaction of both parties the following provisions shall apply--

(i) either party may, by 14 days notice in writing to the other party, require the subject matter of the dispute to be submitted to a single Arbitrator and shall, in such notice, nominate a person to arbitrate upon the subject matter of the dispute;

(ii) the party receiving such notice may, within the said period of 14 days, by a counter notice, either

 (I) accept the Arbitrator nominated by the party serving the original notice or

(II)  nominate not less than two alternative persons to act as such Arbitrator;

(iii) if any one of the persons nominated by the parties is acceptable to both parties of the dispute then the subject matter of the arbitration shall be referred to such Arbitrator as soon as may be after such Arbitrator has indicated his willingness to act as Arbitrator;

(iv) If, after service of such notice and such counter-notice, the parties fail to agree upon an Arbitrator or if an Arbitrator agreed upon has failed to indicate, within 14 days of being so requested, his willingness to act then either the Board or the utility may apply to the Chairman for the time being of the Irish Branch of the Chartered Institute of Arbitrators for the appointment of an arbitrator;

(v) where the Arbitrator is so appointed by the Chairman of the Irish Branch of the Chartered Institute of Arbitrators, he or she shall notify the Board and the utility in writing of his or her appointment as soon as may be thereafter and shall conduct the arbitration in accordance with the rules of the Irish Branch of the said Institute.

(vi) the provisions of the Arbitration Acts, 1954-1998 shall apply to the arbitration and the decision of the Arbitrator in relation to the dispute and all matters connected therewith shall be binding on the parties thereto.

Agreement between the Board and road authorities.

25. The Board may, from time to time, enter into and carry into effect and thereafter from time to time alter, renew or vary contracts, agreements, or arrangements with a relevant road authority in regard to the laying down, making, paving, metalling or keeping in repair of any public road and the light railway thereon or in respect of altering the levels of the whole or any part of any public road in which the Board is authorised to lay down the light railway and the proportion to be paid by them or either of them of the expenses of laying down, making, paving, metalling or keeping in repair or altering the level of such public road and light railway.

Interference with roads.

26. If, in the course of constructing or maintaining the light railway, the Board shall interfere with any public road it shall make good all damage done by it to such road. If any dispute arises between the Board and any relevant road authority it shall be referred to arbitration in accordance with the provisions of Article 24 of this Order.

Rights of utilities.

27. Nothing in this Order shall take away or abridge any power to open or break up any road in which a light railway is laid or any other power vested in any utility for the purpose of laying down, repairing, altering or removing any apparatus. However, in relation to the exercise of such power the following shall apply:

(a) such power shall not be capable of being exercised without the prior consent in writing of the Board, which consent shall not be unreasonably withheld or delayed;

(b) A utility, in exercising such powers with the consent of the Board, shall, in all respects, comply with any reasonable conditions specified by the Board as necessary for or in connection with the construction, maintenance or operation of the light railway or the light railway works for the protection of the light railway.

Expenses of Minister for Public Enterprise.

28. Any expenses incurred by the Minister for Public Enterprise in the exercise of functions under the Act and this Order shall, to such extent as may be determined by the Minister for Finance, be paid to the Minister by the Board.

SCHEDULES

Schedule I

Part I

Description of the works authorised by this Order

Work No. 1

A light railway approximately 167 metres in length consisting of double lines of light railway commencing at match line O, at the junction of Store Street and Amiens Street, and crossing Amiens Street at approximately right angles and turning to run in a northerly direction at ground level along the strip of land bounded by Amiens Street and Harbourmaster Place toward the southern facade of Connolly Station to a point approximately 14 metres south of match line O as shown on Plan No. C(S)-RO 12 O-O

SCHEDULE I

Part 2

Further works authorised by this Order

Work No. 1

Demolish the Connolly Station ramp which commences at the junction of Mayor Street and Amiens Street together with the walls defining the ramp, along Harbourmaster Place and Amiens Street, and sub-structures; the northernmost limit of the demolition works being as shown on Plan No. C(S)-RO 12 O-O and the existing ramp being as shown

Work No. 2

Construct a terraced plaza at main railway station concourse level and extending from the southern face of the main railway station building as shown

Work No. 3

Construct a stop to be called “Connolly stop” at ground level on the strip of land bounded by Amiens Street and Harbourmaster Place and adjacent to the southern face of Connolly Station in the location shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 4

Construct canopies at the stop location described in Work No.3 and as shown

Work No. 5

Construct access stairs, escalators and elevator providing access to and from the stop described in Work No. 3 from and to the terraced plaza described in Work No. 2 at the locations shown in Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 6

Construct pedestrian accesses adjacent to and east and west of the stop described in Work No. 3 providing access to and from Harbourmaster Place and Amiens Street respectively at the locations shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 7

Construct a deck leveller facility to allow access by persons whose mobility is impaired to and from the stop described in Work No. 3 from and to Harbourmaster Place in the location shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 8

Construct a wall with a retaining function over part of its length and with a railing affixed thereto extending along the Harbourmaster Place side of the light railway line as shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 9

Construct an underground electricity sub-station at the north east corner of the junction of Amiens Street and Mayor Street at the location shown in Plan No. C(S)-RO 12 O-O and as shown in detail on Plan Nos. C(S)-ST 12 O-O3, O4 & O8.

Work No. 10

Relocate an electricity sub-station at ground level within the main Connolly Station building with a new access door onto Amiens Street to the location shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 11

Construct an information/retail kiosk at the north east corner of the junction of Amiens Street and Mayor Street at the location shown on Plan No. C(S)-RO 12 O-O and as shown in detail

Work No. 12

Construct footpaths, verges, planting areas and roadway incorporating bus, taxi, private car and bicycle facilities as shown on Plan No. C(S)-RO 12 O-O and as shown in detail on Plan No. C(S)-ST 12 O-O1.

Schedule 2

Land which may be acquired

Schedule 3

Part 1

Buildings etc. to which brackets may be attached.

Part 2

Land upon which poles may be erected

Schedule 4

Basements under public road which may be required

Schedule 5

New roads which may be constructed

Construct a roadway at ground level on the strip of land bounded by Amiens Street and Harbourmaster Place with vehicular access to and from Amiens Street only at the location shown on Plan No. C(S)RO 12 O-O and as shown in detail on Plan No. C(S)ST 12 O-O1.

Schedule 6

Public roads upon which the light railway works may be carried out.

Store Street

Amiens Street

Schedule 7

Rights of way and other easements which may be acquired.

Schedule 8.

Public rights of way which may be extinguished.

Part 2

Private rights which may be extinguished

Schedule 9

Rights of way which may be temporarily interrupted.

Schedule 10

Land which may be temporarily occupied.

Schedule 11

Conditions

1. Prior to the attaching of catenary wires to any building, the applicant is to supply for the agreement of Dublin Corporation appropriate detailed drawings of the proposed connections. In default of agreement between Dublin Corporation and the applicant, the matter should be decided by the Minister for Public Enterprise.

2. It is considered appropriate that advertising should not undermine the character of the public domain. Advertising at Connolly Station stop shall be restricted to that outlined in the EIS drawing. Any deviation or change from this procedure shall be the subject of a normal planning application.

3. Prior to the commencement of development under this Light Rail Order, the applicant shall establish or cause to be established or participate in the establishment of a local liaison committee in respect of this area to represent the interests of all statutory authorities likely to be affected including the relevant local authority, Garda Síochána, utilities, business and residential groups. The composition of the committee should be determined by the traffic management committee established in respect of Line A. The committee established may be incorporated into the similar committee recommended in respect of Line C in view of the close proximity of the areas covered by both applications. A representative from McCann Fitzgerald Solicitors shall be invited to be a member of the committee. Subject to the foregoing the composition of the committee shall be determined by the traffic management committee established in respect of Line A. In the absence of agreement the membership shall be determined by the Minister for Public Enterprise. The applicant shall have a positive responsibility to ensure that all construction works likely to impact on the property and/or business interests of the area are considered by this liaison committee prior to their implementation.

4. Prior to the commencement of works under this Order, the applicant should seek the advice of Dúchas on the archaeological significance of the work proposed. The applicant shall implement any recommendation received from Dúchas. In the event of any disagreement between the applicant and Dúchas on any matter (including the recommendations of Dúchas) the issue shall be determined by the Minister for Public Enterprise.

5. Prior to the commencement of development under this Light Rail Order, the applicant shall submit for the agreement of Dublin Corporation proposals in respect of the following matters relevant to the development at Connolly Station:

(a) Detailed design of the canopies including the following: the materials, colour and texture of the canopies (which shall be self-cleansing) together with details of how the canopies are to interface with the existing new southern elevation and entrance to Connolly Station together with a design of the appropriate night time illumination.

(b) Detailed design of paving including a selection of materials within a spacial footprint defined by the existing ramp area.

(c) Design details of how the proposed new elements interface with the existing listed facade of Connolly Station along Amiens Street.

(d) Design of the kiosk at the entrance of the IFSC including selection of materials and the design of any associated fascia/advertising.

In the absence of agreement between the applicant and Dublin Corporation concerning any of the foregoing matters, the matter in dispute shall be determined by the Minister for Public Enterprise.

EXPLANATORY NOTE.

(This note is not part of the Instrument and does not purport to be a legal interpretation.)

The effect of this order is to confer on Córas Iompair Éireann the necessary powers under the Transport (Dublin Light Rail) Act, 1996 to construct, maintain and operate a light railway system known as Dublin Light Rail (Line C--Abbey Street to Store Street) Order 2000. The plans referred to in the Order are available for inspection or purchase at the Dublin Light Rail Office, Heuston Station, Dublin 8.